NORTH MIDLAND BUILDING LTD v CYDEN HOMES LTD
[2018] BLR 565
COURT OF APPEAL(CIVIL DIVISION)
Before Sir Etherton,Sir Ryder,Lord Justice Coulson
Acts of prevention - JCT Design and Build Contract 2005 - Extension of time - Concurrent delay caused by Contractor - Clause requiring such concurrent delays to be disregarded enforceable - Implied term preventing imposition of liquidated damages.